Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

gropmant_thumb
Ted R. Gropman
fanc_thumb
Christine Z. Fan

This article was originally published on December 3, 2019 on ConsensusDocs. It is reprinted here with permission.

Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date.

Continue reading “Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?”

If You Want to Avoid Prejudgment Interest You Have to Expressly Say So in the Contract, Merely Striking the Interest Provision From the Contract May Not Work

G&G Mech. Constructors, Inc. v. Jeff City Indus., Inc., No. WD80840, 2018 Mo. App. LEXIS 271 (Mar. 20, 2018).

This case arose out of a project in Columbia, Missouri on which Jeff City Industry, Inc. (“JCI”) was the general contractor and G&G Mechanical Constructors, Inc. (“G&G”) was a subcontractor.

The draft subcontract contained an interest provision which provided that overdue payments “shall bear interest at the annual rate of 18% or the highest rate allowed by law, if lower. Retainage shall not be held out of payment.”  JCI struck through this provision, wrote “5% Retiange [sic]” in the margin, initialed it, and sent it to G&G.  G&G also initialed the revision.

When JCI failed to pay G&G for its work, G&G sued JCI for breach of contract, unjust enrichment, and violation of Missouri’s Prompt Pay Act.  A jury returned a verdict against JCI, and the trial court entered a judgment against it which included prejudgment interest at the rate of 9% pursuant to Missouri Revised Statute § 408.020. Continue reading “If You Want to Avoid Prejudgment Interest You Have to Expressly Say So in the Contract, Merely Striking the Interest Provision From the Contract May Not Work”