Delay – Constructlaw.com

New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing

Rad and D’Aprile, Inc. v. Arnell Construction Corp, No. 502464/14, 2019 BL 131606 (NY. Sup. Ct. April 3, 2019)

In June of 2001, Arnell Construction Corp. (“Arnell”) entered into a prime contract to build two sanitation garages in Brooklyn for the New York City Department of Sanitation (the “City”). Arnell subcontracted the project’s masonry work to Rad and D’Aprile, Inc. (“Rad”). After execution of the subcontract, Rad was informed that the start of work would be delayed because the City had not yet obtained ownership or access to all portions of the site. When its work did commence, only limited portions of the site were available. This caused inefficiencies in Rad’s work and caused it to incur increased costs.

Continue reading “New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing” →

Arbitration, Breach of Contract, Delay, Indemnity, Insurance

Boring Through the Details: U.S. District Court Declares Boring Company Dispute Not Covered by Insurance Policies

Maxum Indemnity Co. v. Robbins Co., P.C., No. 1:17-CV-01968, 2018 U.S. Dist. LEXIS 57729 (N.D. Ohio Mar. 28, 2018)

R. Zachary Torres-Fowler

On March 21, 2018, the United States District Court for the Northern District of Ohio granted a motion for judgment on the pleadings in favor of Maxum Indemnity Co. and declared that Maxum has no duty to defend or indemnify The Robbins Company in an international arbitration initiated by a third-party, JCM Northlink, LLC.

Robbins is a designer, manufacturer, and supplier of tunnel-boring machines (“TBMs”) and was engaged by JCM to supply a TBM for Seattle’s Northgate Link Extension project to add additional light rail lines to the city’s existing public transportation system. Maxum insured Robbins under two commercial general liability policies in connection with the Northgate Link Extension project.

Continue reading “Boring Through the Details: U.S. District Court Declares Boring Company Dispute Not Covered by Insurance Policies” →

Delay

Concurrent Delay: Surety—Standing in the Shoes of Subcontractor—Is Barred From Asserting Defense of Concurrent Delay Because Subcontractor Failed to Seek a Time Extension as Required by the Subcontracts

Fid. & Deposit Co. of Md. v. Travelers Cas. & Sur. Co. of Am., 2018 U.S. Dist. LEXIS 162265 (D. Nev., September 21, 2018)

Clark County School District (“CCSD”) hired Big Town Mechanical (“Big Town”) as general contractor to perform HVAC upgrades at five schools. Big Town in turn hired F.A.S.T. Systems (“FAST”) to complete low-voltage work at the schools. Big Town obtained performance bonds from Travelers Casualty and Surety Company of America (“Travelers”) and FAST obtained performance bonds from Fidelity & Deposit Company of Maryland (“F&D”).

Following FAST’s default on its subcontracts, F&D opted to complete FAST’s work and hired a substitute subcontractor, Perini. In May 2012, Perini notified Big Town that it had “substantially completed” all of FAST’s work. After Big Town refused payment, F&D filed suit against Big Town and Travelers in early 2013. In May of 2013, CCSD rejected Big Town’s final payment application, stating that the project was incomplete and claiming there were significant defects in the work. CCSD then sued Travelers seeking specific performance and liquidated damages for delay. Travelers eventually settled CCSD’s suit but through its counterclaim sought reimbursement from F&D for its settlement plus costs expended to complete the project. Continue reading “Concurrent Delay: Surety—Standing in the Shoes of Subcontractor—Is Barred From Asserting Defense of Concurrent Delay Because Subcontractor Failed to Seek a Time Extension as Required by the Subcontracts” →