DC Court Holds that Authority’s Consideration Of Contractor’s Claim on Merits Raises Issue of Fact as to Waiver of Late Notice Defense

TRG Construction, Inc. v. District of Columbia Water & Sewer Authority
2013 D.C. App. LEXIS 257 (May 9, 2013)

Appellant, TRG Construction, Inc. (“TRG”), was hired by the District of Columbia Water and Sewer Authority (“D.C. Water”) to renovate bathrooms at D.C. Water’s central operations facility. When TRG initially contracted with D.C. Water it agreed to complete the bathroom renovations by June 13, 2004. The project suffered delays, however, and the deadline for completion was extended to July 31, 2005. Before that deadline, TRG requested another extension. D.C. Water declined to grant the request. Shortly thereafter, D.C. Water sent TRG a cure notice detailing several alleged deficiencies in TRG’s work. TRG declined to fix the problems asserting that its work was not defective. On September 2, 2005, D.C. Water terminated TRG’s contract for convenience.

Continue reading “DC Court Holds that Authority’s Consideration Of Contractor’s Claim on Merits Raises Issue of Fact as to Waiver of Late Notice Defense”