Georgia Court of Appeals Affirms Superior Court’s Confirmation of Arbitration Award, Finding That Arbitrator Did Not Manifestly Disregard Law Governing the “Modified Total Cost” Approach to Damages

Gainesville Mech., Inc. v. Air Data, Inc., No. A19A0518., 2019 BL 229069 (Ga. Ct. App. June 19, 2019)

cuozzom_thumb
Michelle J. Cuozzo

The First Division of the Georgia Court of Appeals affirmed a superior court’s decision to confirm an arbitration award against Appellant Gainesville Mechanical, Inc. (“Gainesville”) because Gainesville failed to show that the arbitrator manifestly disregarded the law governing the “modified total cost” approach to damages.

Continue reading “Georgia Court of Appeals Affirms Superior Court’s Confirmation of Arbitration Award, Finding That Arbitrator Did Not Manifestly Disregard Law Governing the “Modified Total Cost” Approach to Damages”

New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing

Rad and D’Aprile, Inc. v. Arnell Construction Corp, No. 502464/14, 2019 BL 131606 (NY. Sup. Ct. April 3, 2019)

berrk_thumb
Kristopher Berr

In June of 2001, Arnell Construction Corp. (“Arnell”) entered into a prime contract to build two sanitation garages in Brooklyn for the New York City Department of Sanitation (the “City”).  Arnell subcontracted the project’s masonry work to Rad and D’Aprile, Inc. (“Rad”).  After execution of the subcontract, Rad was informed that the start of work would be delayed because the City had not yet obtained ownership or access to all portions of the site.  When its work did commence, only limited portions of the site were available.  This caused inefficiencies in Rad’s work and caused it to incur increased costs.

Continue reading “New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing”

District Court in Utah Grants Summary Judgment for Contractor Against Insurance Subrogation Claim Based on Contractual Waiver Provision and Statute of Limitations

Aquatherm, LLC v. CentiMark Corp, 2019 BL 13240 (D. Utah Apr. 12, 2019)

conradj_thumb
John H. Conrad

Stag II Lindon LLC and Stag Industrial Inc. (collectively “Stag”) owned a building in Lindon, Utah.  Stag contracted with CentiMark Corp. (“CentiMark”) to perform work on the building’s roof.  CentiMark’s work required it to manipulate, move, and reinstall existing heating cables on the roof.  Shortly after completion of the work, in March of 2014, a fire occurred on the roof which was traced to the location of heat tape, which CentiMark had removed and replaced.

Continue reading “District Court in Utah Grants Summary Judgment for Contractor Against Insurance Subrogation Claim Based on Contractual Waiver Provision and Statute of Limitations”