Defective Specifications

D.W. Wilburn, Inc. v. K. Norman Berry Assocs., No. 2015-CA-001254-MR, 2016 Ky. App. Lexis 206 (Ky. Ct. App. Dec. 22, 2016)

This case arose out of a construction project in which the Oldham County Board of Education (the “Board”) was the owner, K. Norman Berry Associates (“KNBA”) was the architect and D.W. Wilburn (“Wilburn”) was the general contractor. The Board’s contract with Wilburn provided that: (i) change orders must be signed by the architect, contractor, and owner; (ii) claims for additional time, money or delay damages must be submitted within twenty-one days of the event giving rise to the claim; (iii) change orders resolved all claims for time and money relating to the scope of the change order, and (iv) the contractor’s acceptance of final payment waived its claims, except those identified in writing as unsettled at the time of final application for payment.  Pursuant to the contract, the parties executed twenty-one change orders and Wilburn submitted a final payment application and closeout form.

Later, Wilburn was sued by one of its subcontractors for delay to the project. Wilburn then sued KNBA in a third party complaint asserting that KNBA was liable for the delay as a result of its defective plans and specifications.  The trial court granted KNBA summary judgment, dismissing Wilburn’s claim for lack of contractual privity.  Wilburn appealed, and the Court of Appeals reversed.Continue Reading Kentucky Appellate Court Holds That a Contractor May Pursue Claim of Negligent Misrepresentation Against Architect Despite Lack of Contract, the Economic Loss Rule, and Project Waivers