Tag Archives: Eichleay formula

Federal Court Holds That, Under Louisiana Law, a Contractor Need Not Show a Total Work Stoppage to Recover Extended Home Office Overhead Under Eichleay

Team Contrs., L.L.C. v. Waypoint NOLA, L.L.C., No. 16-1131, 2017 U.S. Dist. LEXIS 162172 (E.D. La. Oct. 2, 2017). Waypoint NOLA (“Waypoint”) was the owner of a hotel construction project in New Orleans (the “Project”).  Waypoint contracted with Team Contractors … Continue reading

Posted in Delay | Tagged , , , ,

Federal Circuit Court of Appeals Holds Public Contractor Entitled to Eichleay Overhead Damages for Government-induced Delay of Public Contract Notwithstanding That Its Forces Were Not Totally Idle During Delay

J.P. Altmayer v. R.W. Johnson, 79 F.3d 1129 (Fed. Cir. 1996). GSA had planned to order the carpet and trim for the office by August 1992 but did not do so despite repeated requests from Altmayer who tried to impress … Continue reading

Posted in Delay, General Contractor | Tagged , ,