Tag Archives: Prejudgment Interest

Ohio Supreme Court Holds Contractor Entitled to Prejudgment Interest on Damages for Delay and Disruption; Liquidated/Unliquidated Damages Dichotomy Rejected

Royal Electric Construction Corp. v. Ohio State University, 73 Ohio St. 3d 110, 652 N.W.2d. 687, 1995 Ohio LEXIS 18905 (Ohio Sup. Ct. Aug. 15, 1995) Prejudgment Interest – Contractor that succeeded on delay and disruption claim was entitled to … Continue reading

Posted in Liquidated Damage Provision, Payment dispute | Tagged

District Court in New York Finds Evidence Sufficient to Support Waiver of Written Change Order Requirement and Bad Faith Exception to Enforceability of “No Damage for Delay” Clause in Subcontractor Miller Act Suit

United States of America, for the Use and Benefit of Evergreen Pipeline Construction Co., Inc. v. Me, No. 90 Civ. 5106, 890 F. Supp. 1213, 1995 U.S. Dist. LEXIS 9385 (S.D.N.Y. July 7, 1995) Oral Requests for Extra Work – … Continue reading

Posted in Miller Act, Subcontract | Tagged , , , ,