settlement

Subscribe to settlement

Rad and D’Aprile, Inc. v. Arnell Construction Corp, No. 502464/14, 2019 BL 131606 (NY. Sup. Ct. April 3, 2019)

In June of 2001, Arnell Construction Corp. (“Arnell”) entered into a prime contract to build two sanitation garages in Brooklyn for the New York City Department of Sanitation (the “City”).  Arnell subcontracted the project’s masonry work to Rad and D’Aprile, Inc. (“Rad”).  After execution of the subcontract, Rad was informed that the start of work would be delayed because the City had not yet obtained ownership or access to all portions of the site.  When its work did commence, only limited portions of the site were available.  This caused inefficiencies in Rad’s work and caused it to incur increased costs.Continue Reading New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing

SMJ Gen. Constr., Inc. v. Jet Commer. Constr., LLC, No. S-16785/16985, 2019 BL 131640 (Alaska Apr. 12, 2019)

In 2016, Jet Commercial Construction, LLC (“Jet”) entered into a subcontract with SMJ General Construction, Inc. (“SMJ”) to supply materials and labor for the construction of a restaurant in Hawaii.  The subcontract contained a dispute resolution provision that required the parties to first mediate any dispute and then submit it to arbitration if mediation was unsuccessful.  It also included a choice-of-law and venue provision designating Oklahoma Law and the courts of Cleveland County, Oklahoma for any lawsuits pertaining to the Agreement’s enforcement.Continue Reading Alaska’s Supreme Court Holds That Executing a Settlement Agreement Releases Parties from Contractual Obligation to Arbitrate Disputes