About Constructlaw.comConstructlaw® is an update and discussion of recent trends in construction law and construction litigation. It is edited by Robert E. Heideck, partner in Pepper Hamilton LLP's Construction Law Practice Group. Additional contributors are listed on the Contributors page. For more information about Pepper's Construction Practice Group, click here.
Subscribe via RSS
Subscribe by E-Mail
Recent Past Posts
Tag Archives: State of Michigan Department of Transportation
Michigan Court of Appeals Holds That Contractor Who Failed to Timely Seek a Time Extension Is Barred From Contesting Liquidated Damages
Abhe & Svboda, Inc. v. State of Michigan Department of Transportation, 2017 Mich. App. Lexis 1387 (August 29, 2017) Contractor Abhe & Svboda, Inc. (“A&B”) entered into a contract with the Michigan Department of Transportation (“MDOT”) to clean and paint … Continue reading →