Georgia Court of Appeals Holds That Sovereign Immunity Shields County From Contractor’s Claims Based Upon Unwritten Change Orders

Fulton County v. Soco Contracting Company, Inc., 2017 Ga. App. LEXIS 568 (Ga. Ct. App., November 15, 2017) 

Fulton County contracted with SOCO Construction Company (“SOCO”) to build a cultural center near the Fulton County Airport.  The contract specified that the contract sum and the contract time could only be changed according to County procedure, which required “a written, bilateral agreement (Modification) between the County … and the contractor.”

Adverse weather conditions, design delays, change order requests, and a federal government shutdown allegedly delayed the project.  Despite the County’s program manager listing more than 30 change orders in the project’s change order evaluation log, the County never issued any written change orders, including any change orders extending the contract time to account for the delays.  The County also withheld payment from SOCO.

SOCO sued the County for breach of contract and bad faith performance of contract, and it sought attorney fees and injunctive relief.  Continue reading “Georgia Court of Appeals Holds That Sovereign Immunity Shields County From Contractor’s Claims Based Upon Unwritten Change Orders”

West Virginia Supreme Court Applies Doctrine of Severability to Enforce Lease’s Arbitration Provision, Despite Other Provisions Contemplating Litigation in Court

SWN Prod. Co., LLC v. Long, 2017 W. Va. LEXIS 892 (W. Va. Oct. 18, 2017)

Respondents Richard and Mary Long (“Respondents” or “Lessors”) brought a state court action against Petitioner SWN Production Company, LLC (“Petitioner” or “Lessee”) seeking to recover alleged payments owed pursuant to an oil and gas lease (the “Lease”) entered into between Petitioner and Respondent.

Petitioner filed a motion to compel arbitration, relying on the Lease’s arbitration provision, which reads:  “In the event of a disagreement between Lessor and Lessee concerning this Lease, performance thereunder, or damages caused by Lessee’s operations, the resolution of all such disputes shall be determined by arbitration in accordance with the rules of the American Arbitration Association.” Continue reading “West Virginia Supreme Court Applies Doctrine of Severability to Enforce Lease’s Arbitration Provision, Despite Other Provisions Contemplating Litigation in Court”

Federal District Court in Virginia Holds That Prime Contractor’s Payment Bond Surety Cannot Rely on No-Damages-For-Delay Clause in Subcontract to Limit Liability to Subcontractor Under Miller Act

United States v. John C. Grimberg Co., Case No. 1:16-cv-991, 2017 U.S. Dist. LEXIS 173362 (E.D. Virginia, October 19, 2017)

John C. Grimberg (“Prime Contractor”) was awarded a contract (the “Prime Contract”) to design and complete certain improvements at the FBI Academy in Quantico, Virginia (the “Project”).  Hartford Accident and Indemnity Company (“Surety”) issued payment and performance bonds for the Project pursuant to the Miller Act.  The Prime Contractor thereafter entered into a subcontract (the “Subcontract”) with Kitchens-to-Go (“Subcontractor”) to furnish, install, lease and remove a temporary kitchen facility for the Project.  The Subcontract contained a “no-damages-for-delay” clause, which provided that the Prime Contractor shall not be liable for delays beyond its control and that the Subcontractor is “entitled only to reimbursement for damages for delay actually recovered from the Owner.”  The Subcontract also incorporated the dispute resolution procedures in the Prime Contract, which required that all “disputes arising out of Owner acts, omissions or responsibilities” be submitted through an administrative process with the government’s contracting officer under 41 U.S.C. §§7101 et. seq.

The Subcontract originally contemplated a Project duration of approximately 13 months, ending on April 5, 2014, but was ultimately extended until June 27, 2015.  The Subcontractor submitted its Application for Payment to the Prime Contractor, which included $607,221 for extended rental of the kitchen facilities.  Although the Prime Contractor submitted a payment request to US Department of the Navy (“Owner”), for the extended rental and use of Subcontractor’s temporary kitchen facilities, this request was rejected by the Owner.  The Prime Contractor refused to pay Subcontractor’s Application for Payment and the Subcontractor filed a complaint against the Surety under the Miller Act.  Continue reading “Federal District Court in Virginia Holds That Prime Contractor’s Payment Bond Surety Cannot Rely on No-Damages-For-Delay Clause in Subcontract to Limit Liability to Subcontractor Under Miller Act”