New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing

Rad and D’Aprile, Inc. v. Arnell Construction Corp, No. 502464/14, 2019 BL 131606 (NY. Sup. Ct. April 3, 2019)

berrk_thumb
Kristopher Berr

In June of 2001, Arnell Construction Corp. (“Arnell”) entered into a prime contract to build two sanitation garages in Brooklyn for the New York City Department of Sanitation (the “City”).  Arnell subcontracted the project’s masonry work to Rad and D’Aprile, Inc. (“Rad”).  After execution of the subcontract, Rad was informed that the start of work would be delayed because the City had not yet obtained ownership or access to all portions of the site.  When its work did commence, only limited portions of the site were available.  This caused inefficiencies in Rad’s work and caused it to incur increased costs.

Continue reading “New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing”

Contractor’s Third Party Beneficiary Claim Dismissed Against Designer Where Designer’s Contract with Owner Lacked Clear Intent to Benefit the Contractor

Arco Ingenierosm, S.A. v. CDM Int’l Inc., Civil Action No. 18-12348-PBS, 2019 BL 100779 (D. Mass. Mar. 22, 2019)

eatonl_thumb
Luke Nicholas Eaton

In November 2009, Tropical Storm Ida hit El Salvador, causing flooding, landslides, and the destruction of homes, roads, bridges, schools, health clinics, and other infrastructure.  The United States Agency for International Development (“USAID”) provided $25 million in funding to rebuild damaged infrastructure.  USAID retained Defendant CDM International Inc. (“CDM”) to conduct studies and assessment for the construction of eight schools and one health clinic (the “Projects”) and to create preliminary designs and technical specifications for these Projects.  These preliminary designs were intended to constitute at least thirty percent of final designs for the Projects.  Relying on the preliminary designs created by CDM, Plaintiff Arco Ingenieros, S.A. de C.V. (“ARCO”) submitted bids to act as the design-build contractor for the Projects.  USAID awarded the Projects to ARCO.

Continue reading “Contractor’s Third Party Beneficiary Claim Dismissed Against Designer Where Designer’s Contract with Owner Lacked Clear Intent to Benefit the Contractor”

Connecticut Superior Court Affirms Judgment for Contractor on Claim for Extra Work, Holds Substantial Compliance Satisfies Notice Requirement and Approves Damages Calculated on Variants of the Total Cost Method and Eichleay Formula

Paragon Constr. Co. v. Dep’t of Pub. Works
2013 Conn. Super LEXIS 789 (Conn. Super. Ct. 2013)

The Connecticut Department of Public Works and the Connecticut Department of Corrections (collectively “the State”) solicited bids for the renovation of a correctional center. Paragon Construction Co. (“Paragon”) was awarded the contract, and it subcontracted with MacKenzie Painting Co. (“MacKenzie”) for work relating to de-leading and painting security bars on the windows of the correctional center.

Continue reading “Connecticut Superior Court Affirms Judgment for Contractor on Claim for Extra Work, Holds Substantial Compliance Satisfies Notice Requirement and Approves Damages Calculated on Variants of the Total Cost Method and Eichleay Formula”