New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing

Rad and D’Aprile, Inc. v. Arnell Construction Corp, No. 502464/14, 2019 BL 131606 (NY. Sup. Ct. April 3, 2019)

berrk_thumb
Kristopher Berr

In June of 2001, Arnell Construction Corp. (“Arnell”) entered into a prime contract to build two sanitation garages in Brooklyn for the New York City Department of Sanitation (the “City”).  Arnell subcontracted the project’s masonry work to Rad and D’Aprile, Inc. (“Rad”).  After execution of the subcontract, Rad was informed that the start of work would be delayed because the City had not yet obtained ownership or access to all portions of the site.  When its work did commence, only limited portions of the site were available.  This caused inefficiencies in Rad’s work and caused it to incur increased costs.

Continue reading “New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing”

New York Supreme Court Granted Summary Judgment for Subcontractor Where Contractor Attempted to Utilize Contractual “Pay-When-Paid” Provision to Unreasonably Withhold Payment from Subcontractor

A.E. Rosen Elec. Co. v. Plank, LLC, No. 07862-7, 2019 BL 113951 (Sup. Ct. Mar. 01, 2019)

rosenbem_thumb
Michelle Beth Rosenberg

On March 1, 2019, the Supreme Court of New York, Albany County, granted a subcontractor’s motion for summary judgment on a payment dispute involving a “pay-when-paid” contract provision.

Defendant Plank, LLC (“Contractor”) entered into a construction contract with Dutch Village, LLC (“Owner”) to act as the general contractor for the construction of four apartment buildings (“Project”).  Thereafter, Contractor entered into a subcontract with Plaintiff A.E. Rosen Electrical, Inc. (“Subcontractor”) for electrical work on the Project.  After nine months of work on the Project, a payment dispute arose between the Owner and Contractor.  At that time, Contractor directed the Subcontractor to cease work on the Project.

Continue reading “New York Supreme Court Granted Summary Judgment for Subcontractor Where Contractor Attempted to Utilize Contractual “Pay-When-Paid” Provision to Unreasonably Withhold Payment from Subcontractor”

Federal Court in Louisiana Upholds Suspensive Condition Not Subject Solely to Owner’s Whim

Team Contractors, LLC v. Waypoint Nola, LLC, No. 16-1131, 2019 BL 96133 (E.D. La. Mar. 20, 2019)

andersoe_thumb
Emily D. Anderson

The Eastern District of Louisiana recently denied the motion of a prime contractor (the “Contractor”) for summary judgment on its breach of contract claim against the owner (the “Owner”) of a construction project in New Orleans (the “Project”) where the primary issue involved whether a suspensive condition was enforceable.

Continue reading “Federal Court in Louisiana Upholds Suspensive Condition Not Subject Solely to Owner’s Whim”