Rad and D’Aprile, Inc. v. Arnell Construction Corp, No. 502464/14, 2019 BL 131606 (NY. Sup. Ct. April 3, 2019)

In June of 2001, Arnell Construction Corp. (“Arnell”) entered into a prime contract to build two sanitation garages in Brooklyn for the New York City Department of Sanitation (the “City”).  Arnell subcontracted the project’s masonry work to Rad and D’Aprile, Inc. (“Rad”).  After execution of the subcontract, Rad was informed that the start of work would be delayed because the City had not yet obtained ownership or access to all portions of the site.  When its work did commence, only limited portions of the site were available.  This caused inefficiencies in Rad’s work and caused it to incur increased costs.Continue Reading New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing

Aquatherm, LLC v. CentiMark Corp, 2019 BL 13240 (D. Utah Apr. 12, 2019)

Stag II Lindon LLC and Stag Industrial Inc. (collectively “Stag”) owned a building in Lindon, Utah.  Stag contracted with CentiMark Corp. (“CentiMark”) to perform work on the building’s roof.  CentiMark’s work required it to manipulate, move, and reinstall existing heating cables on the roof.  Shortly after completion of the work, in March of 2014, a fire occurred on the roof which was traced to the location of heat tape, which CentiMark had removed and replaced.Continue Reading District Court in Utah Grants Summary Judgment for Contractor Against Insurance Subrogation Claim Based on Contractual Waiver Provision and Statute of Limitations

Westfield Ins. Co. v. Weaver Cooke Constr., LLC, 2019 BL 129431 (E.D.N.C. Apr. 11, 2019)

This case arises out of the alleged defective construction of a condominium complex in North Carolina.  In 2009, the developer on the project filed suit for the alleged construction defects.  This related coverage lawsuit then ensued between the parties’ insurers regarding a duty to defend the general contractor.Continue Reading Federal Court in North Carolina Enforces Insurers’ Duty to Defend a General Contractor as an Additional Named Insured Under the Subcontractor’s Commercial General Liability Policy

Team Contractors, LLC v. Waypoint Nola, LLC, No. 16-1131, 2019 BL 96133 (E.D. La. Mar. 20, 2019)

The Eastern District of Louisiana recently denied the motion of a prime contractor (the “Contractor”) for summary judgment on its breach of contract claim against the owner (the “Owner”) of a construction project in New Orleans (the “Project”) where the primary issue involved whether a suspensive condition was enforceable.Continue Reading Federal Court in Louisiana Upholds Suspensive Condition Not Subject Solely to Owner’s Whim

Dep’t of Transp. v. Seattle Tunnel Partners, 2019 BL 36988, 2 (Wash. App. Div. 2 Feb. 05, 2019)

On January 8, 2019, the Court of Appeals for the State of Washington reversed and remanded in part a trial court’s grant of summary judgment in a tunnel-boring construction case.  Specifically, the Court clarified that the three-year statute of limitations for negligence claims begins to run as soon as the aggrieved party becomes aware of the factual elements of the claims.  It does not matter whether the underlying cause of the claims remains disputed.Continue Reading The Washington Court of Appeals Clarifies When the Statute of Limitations for a Negligence Claim Begins to Run Under the Discovery Rule