Federal Court in Louisiana Upholds Suspensive Condition Not Subject Solely to Owner’s Whim

Team Contractors, LLC v. Waypoint Nola, LLC, No. 16-1131, 2019 BL 96133 (E.D. La. Mar. 20, 2019)

andersoe_thumb
Emily D. Anderson

The Eastern District of Louisiana recently denied the motion of a prime contractor (the “Contractor”) for summary judgment on its breach of contract claim against the owner (the “Owner”) of a construction project in New Orleans (the “Project”) where the primary issue involved whether a suspensive condition was enforceable.

Continue reading “Federal Court in Louisiana Upholds Suspensive Condition Not Subject Solely to Owner’s Whim”

Federal Court Holds That, Under Louisiana Law, a Contractor Need Not Show a Total Work Stoppage to Recover Extended Home Office Overhead Under Eichleay

Team Contrs., L.L.C. v. Waypoint NOLA, L.L.C., No. 16-1131, 2017 U.S. Dist. LEXIS 162172 (E.D. La. Oct. 2, 2017).

Waypoint NOLA (“Waypoint”) was the owner of a hotel construction project in New Orleans (the “Project”).  Waypoint contracted with Team Contractors (“Team”) to serve as the Project general contractor and HC Architecture (“HCA”) to serve as the Project architect.  HCA, in turn, subcontracted with KLG to prepare the mechanical, electrical, and plumbing (“MEP”) plans.

HCA delivered a complete set of specifications, including KLG’s MEP plans, to Team, and Team began work.  It was later discovered that the MEP plans did not comply with code requirements.  Team was forced to remove and reconstruct the MEP work before proceeding with its work as scheduled.

Team filed suit for breach of contract against Waypoint and for negligence against Waypoint, HCA, and KLG.  Team alleged it experienced delay and incurred damages when it was forced to remove and reconstruct the MEP work.  Its damages included extended home office overhead related to the delay.  Team’s expert used the Eichleay formula to calculate these damages. Continue reading “Federal Court Holds That, Under Louisiana Law, a Contractor Need Not Show a Total Work Stoppage to Recover Extended Home Office Overhead Under Eichleay”